Welcome to Centex Bath. By accessing our website and engaging with our bathroom remodeling services, you agree to comply with and be bound by the following terms and conditions. Please review these terms carefully before using our services.
These terms and conditions govern your use of our website and any services provided by Centex Bath, located at 333 H Street, Chula Vista CA 91910. By accessing this website or requesting our services, you accept these terms in full and without reservation. If you disagree with these terms or any part of these terms, you must not use our website or services.
Centex Bath reserves the right to modify these terms at any time without prior notice. It is your responsibility to review these terms periodically for changes. Your continued use of our website and services following the posting of changes constitutes acceptance of those changes. We recommend checking this page regularly to ensure you are aware of any updates.
All content on this website, including text, graphics, logos, images, and software, is the property of Centex Bath and is protected by applicable copyright and trademark laws. You may view and download content for personal, non-commercial use only. Any unauthorized use of the materials appearing on this website may violate copyright, trademark, and other applicable laws and could result in criminal or civil penalties.
When you request a quote or consultation from Centex Bath, you authorize us to contact you regarding your bathroom remodeling project through the contact information you provide. This may include phone calls, text messages, and emails. We use this information solely for the purpose of providing you with service estimates, scheduling consultations, and communicating about your remodeling project.
All service quotes provided by Centex Bath are estimates based on the information provided at the time of consultation. Final project costs may vary depending on additional factors discovered during the remodeling process, such as underlying structural issues, code compliance requirements, or changes to the scope of work requested by the client. We commit to transparent communication regarding any necessary adjustments to pricing before proceeding with additional work.
Payment terms will be established in writing through a separate service agreement before work begins. Typical projects require a deposit to schedule the work and secure materials, with progress payments due at specified milestones throughout the project. Final payment is due upon project completion and client approval. We accept various payment methods including checks, credit cards, and electronic transfers, subject to the terms outlined in your service agreement.
Centex Bath maintains comprehensive liability insurance and workers compensation coverage for all employees and contractors working on your property. However, we recommend that clients verify their homeowner's insurance policy covers renovation work. While we take every precaution to protect your property during the remodeling process, unforeseen circumstances may arise. Our liability is limited to the direct cost of services provided, and we are not responsible for consequential or incidental damages.
Project timelines provided are estimates based on typical working conditions and material availability. While we strive to complete all projects within the estimated timeframe, delays may occur due to factors beyond our control including weather conditions, material backorders, permit processing delays, or unforeseen structural issues. We commit to keeping you informed of any delays and will work diligently to minimize their impact on your project completion date.
Centex Bath guarantees the quality of our workmanship and will address any defects in our installation work reported within one year of project completion. This warranty covers labor and installation but does not extend to manufacturer defects in materials or products, which are covered under the respective manufacturer's warranty. Normal wear and tear, damage caused by improper use or maintenance, or modifications made by others are not covered under our workmanship warranty.
Client responsibilities include providing accurate information about the project scope, existing conditions, and desired outcomes during the consultation process. You are responsible for obtaining any necessary permissions from homeowner associations, landlords, or other parties as applicable. You must also ensure that our team has clear access to the work area and that pets are secured during work hours. Failure to meet these responsibilities may result in project delays or additional costs.
Centex Bath respects your privacy and is committed to protecting your personal information. We collect only the information necessary to provide our services and communicate with you about your project. We do not sell, trade, or otherwise transfer your personal information to outside parties except as required to complete your project or as required by law. For detailed information about how we handle your data, please review our Privacy Policy available on our website.
These terms and conditions are governed by and construed in accordance with the laws of the State of California. Any disputes arising from these terms or your use of our services shall be subject to the exclusive jurisdiction of the courts in San Diego County, California. If any provision of these terms is found to be invalid or unenforceable, the remaining provisions shall continue in full force and effect. For questions regarding these terms, please contact us at [email protected] or call us at +1 (213) 802-1933.